The blast furnace gas fired power plant in Velsen (VN24) is located in the north of the Netherlands along the “Noordzee kanaal”. The unit with a capacity of approximately 459 MW has been commissioned in 1974 and has been in operation until December 2012 for more than 200.000 hours. The lifetime of the entire unit will be extended till 2026. It has been decided that the current 550 MVA, 21kV, cos φ 0.8, 50Hz, H2 directly cooled generator will be replaced. It has been decided to start tendering for an air-cooled generator minimal 310 MVA, cos φ 0.8 and 50 Hz including excitation system which should replace the current THDD 115/59 generator. In addition to the design of the new generator special attention has to be paid to; .Removal of all existing systems which become obsolete. .Meeting the sound limits and other emission limits resulting from the environmental permits. - the foundation and the static and dynamic loads induced on it - the coupling with the existing steam turbine - connection to the existing cooling system (condensate) - connection to the existing lubrication system - connection to the existing electrical system - Replacement of the existing excitation system with a new system.Either a dynamic or static system is possible. - integration within the existing electrical system (short-circuit power, load flow calculations etc) - integration into the existing DCS - adjustments to the generator protection - adjusting steam turbine control/protection due to the smaller rated power of the generator When the offered product has a different rated voltage than 21 kV +/- 10 % then additional measures should be considered to comply with the requirements of the Dutch grid-, system- and metering code as issued by the Netherlands Competition Authority such as: - Replacement of the step-up transformer - etc Replacing the generator must not adversely affect the vibration levels of the powertrain.
Deadline
De termijn voor de ontvangst van de offertes was 2013-04-19.
De aanbesteding werd gepubliceerd op 2013-03-01.
Aankondiging van een opdracht (2013-03-01) Object Toepassingsgebied van de aanbesteding
Titel: Generatoraggregaten
Hoeveelheid of omvang:
The blast furnace gas fired power plant in Velsen (VN24) is located in the north of the Netherlands along the“Noordzee kanaal”. The unit with a capacity of approximately 459 MW has been commissioned in 1974 andhas been in operation until December 2012 for more than 200.000 hours. The lifetime of the entire unit will beextended till 2026. It has been decided that the current 550 MVA, 21kV, cos φ 0.8, 50Hz, H2 directly cooledgenerator will be replaced.Therefore it has been decided to start tendering for an air-cooled generator minimal 310 MVA, cos φ 0.8 and 50 Hz including excitation system whichshould replace the current THDD 115/59 generator.In addition to the design of the new generator special attention has to be paid to;- the foundation and the static and dynamic loads induced on it- the coupling with the existing steam turbine- connection to the existing cooling system (condensate)- connection to the existing lubrication system.Meeting the sound limits and other emission limits resulting from the environmental permits.- connection to the existing electrical system- integration within the existing electrical system (short-circuit power, load flow calculations etc)- integration into the existing DCS- adjustments to the generator protection- adjusting steam turbine control/protection due to the smaller rated power of the generatorWhen the offered product has a different rated voltage than 21 kV +/- 10 % then additional measures shouldbe considered to comply with the requirements of the Dutch grid-, system- and metering code as issued by theNetherlands Competition Authority, such as:- Replacement of the step-up transformer- EtcReplacing the generator must not adversely affect the vibration levels of the powertrain.The works includes but is not limited to:- Removing the current generator with all the associated auxiliary systems which are no longer be (re)used- Transport of all removed components off-site back to the Supplier- Design, manufacture, certificating, testing (including FAT), transport , installation and commissioning of a new air-cooledgenerator according to IEC specifications.- HAZOP / HAZID / SIL assessments- Connection (and if required modifications) of all (sub)systems and structures- All necessary works on existing structures and systems to realise the above items- All (sub)systems, both individual and as a whole have to be commissioned and tested (including SAT).The placement of the new generator and the removal of the existing excitation system will change the load onthe turbine-table and its foundation and will change the dynamic behaviour of the powertrain. Part of the scopeof the Tender Phase is the assessment whether the offered solution is feasible to integrate within the existing power plant.
The blast furnace gas fired power plant in Velsen (VN24) is located in the north of the Netherlands along the“Noordzee kanaal”. The unit with a capacity of approximately 459 MW has been commissioned in 1974 andhas been in operation until December 2012 for more than 200.000 hours. The lifetime of the entire unit will beextended till 2026. It has been decided that the current 550 MVA, 21kV, cos φ 0.8, 50Hz, H2 directly cooledgenerator will be replaced.Therefore it has been decided to start tendering for an air-cooled generator minimal 310 MVA, cos φ 0.8 and 50 Hz including excitation system whichshould replace the current THDD 115/59 generator.In addition to the design of the new generator special attention has to be paid to;- the foundation and the static and dynamic loads induced on it- the coupling with the existing steam turbine- connection to the existing cooling system (condensate)- connection to the existing lubrication system.Meeting the sound limits and other emission limits resulting from the environmental permits.- connection to the existing electrical system- integration within the existing electrical system (short-circuit power, load flow calculations etc)- integration into the existing DCS- adjustments to the generator protection- adjusting steam turbine control/protection due to the smaller rated power of the generatorWhen the offered product has a different rated voltage than 21 kV +/- 10 % then additional measures shouldbe considered to comply with the requirements of the Dutch grid-, system- and metering code as issued by theNetherlands Competition Authority, such as:- Replacement of the step-up transformer- EtcReplacing the generator must not adversely affect the vibration levels of the powertrain.The works includes but is not limited to:- Removing the current generator with all the associated auxiliary systems which are no longer be (re)used- Transport of all removed components off-site back to the Supplier- Design, manufacture, certificating, testing (including FAT), transport , installation and commissioning of a new air-cooledgenerator according to IEC specifications.- HAZOP / HAZID / SIL assessments- Connection (and if required modifications) of all (sub)systems and structures- All necessary works on existing structures and systems to realise the above items- All (sub)systems, both individual and as a whole have to be commissioned and tested (including SAT).The placement of the new generator and the removal of the existing excitation system will change the load onthe turbine-table and its foundation and will change the dynamic behaviour of the powertrain. Part of the scopeof the Tender Phase is the assessment whether the offered solution is feasible to integrate within the existing power plant.
Aankondigingsmetadata
Originele taal: Engels 🗣️
Documenttype: Aankondiging van een opdracht
Aard van de opdracht: Werken
Regelgeving: Europese Unie
Gemeenschappelijke woordenlijst overheidsopdrachten (CPV)
Code: Generatoraggregaten📦
Procedure
Type procedure: Procedure van gunning via onderhandelingen
Type bod: Inschrijving voor alle percelen
Gunningscriteria
Uit economisch oogpunt voordeligste inschrijving
1. The application must be signed and submitted in writing in one hard copy original, being loose-leaf initialed on each page;one digital copy (CD). Digital copy shall include all documents, including scans of original signedletters and declarations. Hardcopies and/or physical data media should be put in a sealed envelope. Each application shall be marked with the EU notification number and be marked as 'confidential'.
2. For convenience and efficiency, the employer would like to see the application structured according to the numbering in Section III.2) and should contain the requested information in the respective categories. The employer reserves the right to disregard information not placed in the herefore provided categories. Indications to earlier applications are not sufficient for verification and will be disregarded.
3. NUON reserves the right to demand further statements and proof (including minimum requirements).Furthermore, it reserves the right to request a personal presentation or visit of company or reference site of a candidate to verify for example the self-declarations. Applicants are not entitled to claim an additional demand or a visit or to do a personal presentation.
4. Questions are exclusively to be sent via email to the contact point until 7 calendar days before the application deadline. Thereafter, incoming questions are not considered. The employer will try to reply in a timelymanner.
5. Request to participate shall be delivered to the contact person in I.1 no later than on the date and time stated in section IV.3.4.
6. Nuon preserves the right to substitute itself during the pre-qualification procedure and/or the tenderprocedure and/or to assign the Contract or after award thereof to another N.V. Nuon Energy subsidiary. Equivalent guarantees will apply on behalf of the other N.V. Nuon Energy subsidiairy as for Nuon. By submitting a Request to Qualify Respondent accepts that Nuon is entitled to substitute itself and/or to assign the Contract by or to another N.V. Nuon Energy subsidiary.
7.Under no circumstance shall Employer be liable for any costs or expenses, incurred by the responding party in connection with the party's Request to Qualify or any resulting Tender Procedure.
8. Nuon reserves the right to suspend or terminate the Tender Procedure either entirely or parts thereof, either temporarily or definitively. In addition, Employer has no obligation to enter in to any agreement.
9. This Contract Announcement and Tender Procedure are subject to the relevant provisions of directive2004/17 EC of the European Parliament and by its inforcement under Dutch law (besluit van 16.7.2005 "Bass"and the Wet Implementatie Rechtsbeschermingsrichtlijnen Aanbesteden "Wira"). Any dispute resulting from thisTender procedure shall be dealt with in accordance therewith.
10. Employer is authorized to verify the references given, including by requesting Respondents that declarationsmade by employers of the quoted reference projects will be sent directly to Employer, or by asking for auditedstatements. Employer may also require the Respondents to supplement or clarify the certificates and documents submitted.
The specifications for contract awarding result from the Invitation To Tender (ITT). For reasons of maximum transparency, the employer announces some general rules in advance. There is, however, no entitlement for employer to comply with them. Therefore, specifications and changes can occur in the context of the ITT:
1. Contract award requires the approval of the board of Employer and Vattenfall AB
2. Contract award is subject to existing permits under public law.
3. Contract award is subject to the economically viable implementation of the services to bedetermined by the employer.
1. The application must be signed and submitted in writing in one hard copy original, being loose-leaf initialed on each page;one digital copy (CD). Digital copy shall include all documents, including scans of original signedletters and declarations. Hardcopies and/or physical data media should be put in a sealed envelope. Each application shall be marked with the EU notification number and be marked as 'confidential'.
2. For convenience and efficiency, the employer would like to see the application structured according to the numbering in Section III.2) and should contain the requested information in the respective categories. The employer reserves the right to disregard information not placed in the herefore provided categories. Indications to earlier applications are not sufficient for verification and will be disregarded.
3. NUON reserves the right to demand further statements and proof (including minimum requirements).Furthermore, it reserves the right to request a personal presentation or visit of company or reference site of a candidate to verify for example the self-declarations. Applicants are not entitled to claim an additional demand or a visit or to do a personal presentation.
4. Questions are exclusively to be sent via email to the contact point until 7 calendar days before the application deadline. Thereafter, incoming questions are not considered. The employer will try to reply in a timelymanner.
5. Request to participate shall be delivered to the contact person in I.1 no later than on the date and time stated in section IV.3.4.
6. Nuon preserves the right to substitute itself during the pre-qualification procedure and/or the tenderprocedure and/or to assign the Contract or after award thereof to another N.V. Nuon Energy subsidiary. Equivalent guarantees will apply on behalf of the other N.V. Nuon Energy subsidiairy as for Nuon. By submitting a Request to Qualify Respondent accepts that Nuon is entitled to substitute itself and/or to assign the Contract by or to another N.V. Nuon Energy subsidiary.
7.Under no circumstance shall Employer be liable for any costs or expenses, incurred by the responding party in connection with the party's Request to Qualify or any resulting Tender Procedure.
8. Nuon reserves the right to suspend or terminate the Tender Procedure either entirely or parts thereof, either temporarily or definitively. In addition, Employer has no obligation to enter in to any agreement.
9. This Contract Announcement and Tender Procedure are subject to the relevant provisions of directive2004/17 EC of the European Parliament and by its inforcement under Dutch law (besluit van 16.7.2005 "Bass"and the Wet Implementatie Rechtsbeschermingsrichtlijnen Aanbesteden "Wira"). Any dispute resulting from thisTender procedure shall be dealt with in accordance therewith.
10. Employer is authorized to verify the references given, including by requesting Respondents that declarationsmade by employers of the quoted reference projects will be sent directly to Employer, or by asking for auditedstatements. Employer may also require the Respondents to supplement or clarify the certificates and documents submitted.
The specifications for contract awarding result from the Invitation To Tender (ITT). For reasons of maximum transparency, the employer announces some general rules in advance. There is, however, no entitlement for employer to comply with them. Therefore, specifications and changes can occur in the context of the ITT:
1. Contract award requires the approval of the board of Employer and Vattenfall AB
2. Contract award is subject to existing permits under public law.
3. Contract award is subject to the economically viable implementation of the services to bedetermined by the employer.
Object Toepassingsgebied van de aanbesteding
Korte beschrijving:
The blast furnace gas fired power plant in Velsen (VN24) is located in the north of the Netherlands along the
“Noordzee kanaal”. The unit with a capacity of approximately 459 MW has been commissioned in 1974 and
has been in operation until December 2012 for more than 200.000 hours. The lifetime of the entire unit will be
extended till 2026. It has been decided that the current 550 MVA, 21kV, cos φ 0.8, 50Hz, H2 directly cooled
generator will be replaced.
It has been decided to start tendering for an air-cooled generator minimal 310 MVA, cos φ 0.8 and 50 Hz including excitation system which
should replace the current THDD 115/59 generator.
In addition to the design of the new generator special attention has to be paid to;
.Removal of all existing systems which become obsolete.
.Meeting the sound limits and other emission limits resulting from the environmental permits.
- the foundation and the static and dynamic loads induced on it
- the coupling with the existing steam turbine
- connection to the existing cooling system (condensate)
- connection to the existing lubrication system
- connection to the existing electrical system
- Replacement of the existing excitation system with a new system.Either a dynamic or static system is possible.
- integration within the existing electrical system (short-circuit power, load flow calculations etc)
- integration into the existing DCS
- adjustments to the generator protection
- adjusting steam turbine control/protection due to the smaller rated power of the generator
When the offered product has a different rated voltage than 21 kV +/- 10 % then additional measures should
be considered to comply with the requirements of the Dutch grid-, system- and metering code as issued by the
Netherlands Competition Authority such as:
- Replacement of the step-up transformer
- etc
Replacing the generator must not adversely affect the vibration levels of the powertrain.
Varianten worden geaccepteerd ✅
Hoeveelheid of omvang:
The blast furnace gas fired power plant in Velsen (VN24) is located in the north of the Netherlands along the
“Noordzee kanaal”. The unit with a capacity of approximately 459 MW has been commissioned in 1974 and
has been in operation until December 2012 for more than 200.000 hours. The lifetime of the entire unit will be
extended till 2026. It has been decided that the current 550 MVA, 21kV, cos φ 0.8, 50Hz, H2 directly cooled
generator will be replaced.
Therefore it has been decided to start tendering for an air-cooled generator minimal 310 MVA, cos φ 0.8 and 50 Hz including excitation system which
should replace the current THDD 115/59 generator.
In addition to the design of the new generator special attention has to be paid to;
- the foundation and the static and dynamic loads induced on it
- the coupling with the existing steam turbine
- connection to the existing cooling system (condensate)
- connection to the existing lubrication system
.Meeting the sound limits and other emission limits resulting from the environmental permits.
- connection to the existing electrical system
- integration within the existing electrical system (short-circuit power, load flow calculations etc)
- integration into the existing DCS
- adjustments to the generator protection
- adjusting steam turbine control/protection due to the smaller rated power of the generator
When the offered product has a different rated voltage than 21 kV +/- 10 % then additional measures should
be considered to comply with the requirements of the Dutch grid-, system- and metering code as issued by the
Netherlands Competition Authority, such as:
- Replacement of the step-up transformer
- Etc
Replacing the generator must not adversely affect the vibration levels of the powertrain.
The works includes but is not limited to:
- Removing the current generator with all the associated auxiliary systems which are no longer be (re)used
- Transport of all removed components off-site back to the Supplier
- Design, manufacture, certificating, testing (including FAT), transport , installation and commissioning of a new air-cooled
generator according to IEC specifications.
- HAZOP / HAZID / SIL assessments
- Connection (and if required modifications) of all (sub)systems and structures
- All necessary works on existing structures and systems to realise the above items
- All (sub)systems, both individual and as a whole have to be commissioned and tested (including SAT).
The placement of the new generator and the removal of the existing excitation system will change the load on
the turbine-table and its foundation and will change the dynamic behaviour of the powertrain. Part of the scope
of the Tender Phase is the assessment whether the offered solution is feasible to integrate within the existing power plant.
Plaats van uitvoering
Hoofdlocatie of plaats van uitvoering: Velsen
Juridische, economische, financiële en technische informatie Voorwaarden voor deelname
Geschiktheid om de beroepsactiviteit uit te oefenen:
Selection of Tenderers shall be based on the following:
a. First of all the application will be reviewed on layout requirements and consistency. When information is missing, not consistent, and or information differs from common practise, NUON can expel the respondent from the procedure. If the information is not clear or some information is missing, NUON has the right, but is not obliged, to ask for additional information.
Geschiktheid om de beroepsactiviteit uit te oefenen
a. First of all the application will be reviewed on layout requirements and consistency. When information is missing, not consistent, and or information differs from common practise, NUON can expel the respondent from the procedure. If the information is not clear or some information is missing, NUON has the right, but is not obliged, to ask for additional information.
b. Second the respondent will be checked for excluding criteria. If such a criterium is applicable to a respondent, respondent will be excluded from further participation in this Tender
c. Third the respondent will be checked for minimum requirements. Respondents that do not comply with all minimum requirements as set out in this Contract Announcement will be excluded from further participation in this Tender
d)Fourth the respondent will be evaluated according the Selection Criteria. Top 5 respondents will be invited to tender.
EXCLUDING CRITERIA
Respondent has to declare and to submit:
a) Respondent is not convicted by final judgement for one or more reasons as described in Article 45 paragraph 1 of Directive 2004/18/EG of the European Parliament and in its enforcement under Dutch law, amongst others,the ‘Besluit Aanbestedingen Speciale Sectoren, BASS, 409, 16 juli 2005'
Geschiktheid om de beroepsactiviteit uit te oefenen
a) Respondent is not convicted by final judgement for one or more reasons as described in Article 45 paragraph 1 of Directive 2004/18/EG of the European Parliament and in its enforcement under Dutch law, amongst others,the ‘Besluit Aanbestedingen Speciale Sectoren, BASS, 409, 16 juli 2005'
Information part of your Request to Qualify: own declaration by duly authorized representative
Information required at conditional contract award: a declaration, no more than three months old, from an Independent (governmental) authority or entity mandated to issue such declaration.
b. Respondent is not bankrupt, has not been liquidated, has not been granted a moratorium or has made any arrangements with creditors to prevent such events; nor that Respondent's activities have not been stopped due to such events. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than three months old, by the clerk of the district court of the domicile or the location of the registered office of Respondent.
Geschiktheid om de beroepsactiviteit uit te oefenen
b. Respondent is not bankrupt, has not been liquidated, has not been granted a moratorium or has made any arrangements with creditors to prevent such events; nor that Respondent's activities have not been stopped due to such events. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than three months old, by the clerk of the district court of the domicile or the location of the registered office of Respondent.
c. No proceedings are conducted against the Respondent that may result in bankruptcy, liquidation or a moratorium or an arrangement with creditors to prevent such events. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than three months old, by the clerk of the district court of the domicile or
Geschiktheid om de beroepsactiviteit uit te oefenen
c. No proceedings are conducted against the Respondent that may result in bankruptcy, liquidation or a moratorium or an arrangement with creditors to prevent such events. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than three months old, by the clerk of the district court of the domicile or
d. Respondent has complied with all his obligations with regard to the payment of social insurance contributions in accordance with the statutory provisions.
Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than 3 months old, from the executive
e. Respondent has complied with all his obligations with regard to paying his taxes. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than 3 months old, from the tax authorities.
Geschiktheid om de beroepsactiviteit uit te oefenen
e. Respondent has complied with all his obligations with regard to paying his taxes. Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: a declaration, no more than 3 months old, from the tax authorities.
f. Respondent is registered in the register of companies.
Information part of your Request to Qualify: certificates of registration
Information required at conditional contract award: no additional information required.
g. Respondent is not convicted by final judgement of any offence concerning its professional conduct, nor has been guilty of grave professional misconduct.
Information part of your Request to Qualify: own declaration by duly authorized representative Information required at conditional contract award: own declaration by duly authorized representative
h. If the Respondent is a branch, subsidiary or operating company of a holding company or a group of companies, and wishes to use the consolidated financial information of the holding company or group of companies for the purposes of his Request to Qualify, the holding company or group of companies shall provide a Parent Company Guarantee in which it accepts liability on behalf of its subsidiary for the complete and correct execution of the announced Contract.
Geschiktheid om de beroepsactiviteit uit te oefenen
h. If the Respondent is a branch, subsidiary or operating company of a holding company or a group of companies, and wishes to use the consolidated financial information of the holding company or group of companies for the purposes of his Request to Qualify, the holding company or group of companies shall provide a Parent Company Guarantee in which it accepts liability on behalf of its subsidiary for the complete and correct execution of the announced Contract.
i. All declarations of the Respondent in the Request to Qualify are done by duly authorized representative(s).
Information part of your Request to Qualify:
proof of duly authorization of representative(s)
Economische en financiële draagkracht:
Minimum Requirements:
Information and formalities necessary for evaluating if the requirements are met: Respondent,or its parent(incase of h.above)shall have the reputable and healthy financial standing necessary to execute the announced contract with the corresponding risk profile and is in a position to provide for all required financial guarantees,financial coverage of project risk, and mitigation of financial risks to Employer.
Information and formalities necessary for evaluating if the requirements are met: Respondent,or its parent(incase of h.above)shall have the reputable and healthy financial standing necessary to execute the announced contract with the corresponding risk profile and is in a position to provide for all required financial guarantees,financial coverage of project risk, and mitigation of financial risks to Employer.
Information part of your Request to Qualify:
A signed statement issued by a financial institution with at least an A by Standard & Poor's or Moody's on the liquidity, solvency and profitability of the Respondent (or its parent in case of h above), that demonstrates that the financial strength of the Respondent or parent is such that he is capable of executing the announced contract.
A signed statement issued by a financial institution with at least an A by Standard & Poor's or Moody's on the liquidity, solvency and profitability of the Respondent (or its parent in case of h above), that demonstrates that the financial strength of the Respondent or parent is such that he is capable of executing the announced contract.
Full audited, consolidated annual reports, including management report and explanatory notes and with a non-qualified auditor opinion, for the most recent three years, of the Respondent and, in case of h., its parent. Incase of a Joint Venture, please include this information for each partner. In the case of consolidated annualreports, additional financial information must be provided that relates specifically to the field of business relatedto the scope of the announced contract.
Full audited, consolidated annual reports, including management report and explanatory notes and with a non-qualified auditor opinion, for the most recent three years, of the Respondent and, in case of h., its parent. Incase of a Joint Venture, please include this information for each partner. In the case of consolidated annualreports, additional financial information must be provided that relates specifically to the field of business relatedto the scope of the announced contract.
Information required at conditional contract award: No additional information required.
a. full credit check and assessment will be part of the evaluation procedure. The minimum required turnover for the Respondent, or its parent is at least three times the contract value.
b. At contracting Respondent is willing to issue a Performance Security in the form of an on-demand bankguarantee in a form and amount acceptable to Vattenfall and by an independent third party bank with aminimum A-/A3 (rating by Standard Poor's and/or Moody's), in the amount of 10 % of the Contract value, valid until the end of the defects notification period under the Contract.
b. At contracting Respondent is willing to issue a Performance Security in the form of an on-demand bankguarantee in a form and amount acceptable to Vattenfall and by an independent third party bank with aminimum A-/A3 (rating by Standard Poor's and/or Moody's), in the amount of 10 % of the Contract value, valid until the end of the defects notification period under the Contract.
Duly signed declaration from the Respondent stating its unconditional willingness to issue such performance guarantee at award of the Contract.
Information at conditional contract award Duly signed Performance Guarantee part of the Contract andaccording to the format included in the Invitation to Tender.
c.At contract award, Respondent is willing to issue security for any advance payments with advance payment guarantees in a form and amount acceptable to Vattenfall and issued by an independant third party bank with a minimum rating of A-/A3 (rating by Standard Poor's and/or Moody's). Information part of the Respondent's Application: duly signed declaration from the Respondent stating its unconditional willingness to issue such guarantee at contract award. Information required at conditional contract award: duly signed advance payment guarantee part of the contract and according to the format included in the invitation to tender.
c.At contract award, Respondent is willing to issue security for any advance payments with advance payment guarantees in a form and amount acceptable to Vattenfall and issued by an independant third party bank with a minimum rating of A-/A3 (rating by Standard Poor's and/or Moody's). Information part of the Respondent's Application: duly signed declaration from the Respondent stating its unconditional willingness to issue such guarantee at contract award. Information required at conditional contract award: duly signed advance payment guarantee part of the contract and according to the format included in the invitation to tender.
d. If a Respondent is a consortium, the requirements in III.2.1 and III.2.2 are applicable to each member individually however the consortium must comply with one and a half times the minimum average annual turnover figure for a single company. The requirements in III.2.3. are applicable to the consortium as a whole.
d. If a Respondent is a consortium, the requirements in III.2.1 and III.2.2 are applicable to each member individually however the consortium must comply with one and a half times the minimum average annual turnover figure for a single company. The requirements in III.2.3. are applicable to the consortium as a whole.
e. If a parent of the Respondent expresses the intent
to guarantee the performance of the Respondent
under the Contract, the financial standing of the parent
needs to be submitted for prequalification purposes. In
that case the information on the financial standing of the
parent will be used in the evaluation of the minimum
and weighted requirements. The parent should also
submit all doc's under III.2.1.a/i (except for h).
Technische en professionele bekwaamheid:
Respondent shall be an established and experienced
contractor in the field of control works of comparable
size and scope, and shall be experienced in the
(detailed) engineering and local project management as
required for the Generator Replacement Velsen 24 project.
Respondent shall have firm representation in The
Netherlands responsible for, or participating in the
major part of the (local) project management and
communication with the Employer. (Further details in
the Invitation to Tender).
Information part of your Request to Qualify:
Clear and comprehensive description of the most
relevant reference project including description of
the organization of and responsibility for each of the
mentioned activities. In case Respondent is a Joint
Venture, please clearly describe which responsibility is
assigned to each participant.
Information at conditional contract award: No additional
information required.
b.Respondent and its Subcontractors shall be VCA or SCC (or equivalent) certified as company
All individual Respondent employees and Subcontractors' employees that will work at Vattenfall operational areas shall be individually IOSH, VCA, SCC 17 or SCC 18 (or equivalent) certified (SCC 16 and SSG Entre are not considered equivalent)
Respondent is willing and able to guarantee and show evidence, at first notice, of the Skill/Education/Experience of all individual employees of both its own company and its Subcontractors
Respondent shall use a similar capability assessment and apply the same Health & Safety requirements for its Subcontractors
Information part of your Request to
Qualify:Authenticated copies of relevant certificates or
details on the HSE management system, its implementation
and any ongoing certification. A completed version of
the HSE questionnaire(I.1)
c. Respondent shall have (or demonstrate that he
will have at the time of Contract award) – adequate
knowledge of and experience with Dutch working
conditions, environmental codes and legislation, so
as to be able to fully comply with all relevant rules and
regulations.
Own declaration (including elaborations on relevant
reference projects and/or proposed partner to
adequately cover for this aspect).
d. Respondent is able to demonstrate that he can at
least raise resources to meet the envisaged project
planning as indicated above. Please be aware that
Employer reserves the right to shift this planning to
accommodate changes in the project planning or
requirements of Tenderers.
Own declaration and workload vs. resource planning.
e. Respondent has been actively involved in at least 1
project of comparable size and complexity since 2002.
Own declaration and detailed project descriptions,
including Respondent's activities deployed in it,
accompanied by a detailed reference list indicating the
customer, roles and responsibilities of Respondent,
the scope and contract values for relevant projects of
similar size and complexity, executed by Respondent
Selection Criteria:
Respondent has to submit and will be selected on:
1)HSE (25 points):Respondent will be selected on their HSE record(as per HSE questionaire)
The Respondent with the best HSE record will receive 25 points ,the Respondent with the weakest HSE record will receive 0 points and so on.
2)Respondent has been actively involved in more than 1 project of comparable size ans complexity since 2002.
The most experienced contractor will receive 75 points ,the least experienced contractor will receive 0 points and so on.
Uitvoering van de opdracht
Vereiste deposito's en garanties:
Conditions will be described in the tender documents (after the prequalification phase)
Belangrijkste financieringsvoorwaarden en betalingsregelingen en/of verwijzing naar de relevante bepalingen die daarop van toepassing zijn:
Conditions will be described in the tender documents (after the prequalification phase)
Rechtsvorm van de combinatie van ondernemers aan wie de opdracht wordt gegund:
If a consortium wants to qualify ,the consortium should take preferably the form of a “Vennootschap onder Firma” according to the Dutch Civil Code or another cooperation form that can be registered by a Chamber of Commerce and which has no legal consequences for the liability of the members of the consortium; all members shall be fully liable to the Employer ("hoofdelijk aansprakelijk").
Rechtsvorm van de combinatie van ondernemers aan wie de opdracht wordt gegund
If a consortium wants to qualify ,the consortium should take preferably the form of a “Vennootschap onder Firma” according to the Dutch Civil Code or another cooperation form that can be registered by a Chamber of Commerce and which has no legal consequences for the liability of the members of the consortium; all members shall be fully liable to the Employer ("hoofdelijk aansprakelijk").
The obligations, risks and liabilities imposed on the Respondent by any contract as a result of this Tender process (if awarded) shall be guaranteed by the partners in that Joint Venture jointly and severally.The Request to Qualify and any resulting Tender and/or Contract shall be signed for each of those parties by the person or persons authorized to make legally valid commitments; In the Request to Qualify and subsequent Tender, the Respondent shall submit proof (to the satisfaction of Nuon) that the agreement amongst the Joint Venture partners provides that: if a Joint Venture partner goes into liquidation or has a receiving order issued against it, such partner will consent to, and the other partner(s) shall procure that all construction equipment,including without limitation tools, computer programs, and software furnished by the partner in question, and all Subcontracts entered into by it, shall continue to be available, or, as the case may be, shall be assigned to the other partner(s), and the structure and membership of the Joint Venture shall be maintained throughout the validity period of the Qualification and any subsequent Tender and/or Contract.
Rechtsvorm van de combinatie van ondernemers aan wie de opdracht wordt gegund
The obligations, risks and liabilities imposed on the Respondent by any contract as a result of this Tender process (if awarded) shall be guaranteed by the partners in that Joint Venture jointly and severally.The Request to Qualify and any resulting Tender and/or Contract shall be signed for each of those parties by the person or persons authorized to make legally valid commitments; In the Request to Qualify and subsequent Tender, the Respondent shall submit proof (to the satisfaction of Nuon) that the agreement amongst the Joint Venture partners provides that: if a Joint Venture partner goes into liquidation or has a receiving order issued against it, such partner will consent to, and the other partner(s) shall procure that all construction equipment,including without limitation tools, computer programs, and software furnished by the partner in question, and all Subcontracts entered into by it, shall continue to be available, or, as the case may be, shall be assigned to the other partner(s), and the structure and membership of the Joint Venture shall be maintained throughout the validity period of the Qualification and any subsequent Tender and/or Contract.
In case Respondent belongs to the same group company and/or service providers or are affiliated to each other by way of annual accounts or if they are under (final) control by the same natural person(s) and/or parent company, only one of the Respondents shall be admitted to the Tendering Procedure as a Respondent and/or subcontractor (which ever applies) – to be decided upon by the Employer.
Rechtsvorm van de combinatie van ondernemers aan wie de opdracht wordt gegund
In case Respondent belongs to the same group company and/or service providers or are affiliated to each other by way of annual accounts or if they are under (final) control by the same natural person(s) and/or parent company, only one of the Respondents shall be admitted to the Tendering Procedure as a Respondent and/or subcontractor (which ever applies) – to be decided upon by the Employer.
Andere bijzondere voorwaarden:
Conditions will be described in the tender dokuments (after the prequalification phase)
Procedure Talen
Taal: Engels 🗣️
Aanbestedende dienst Identiteit
Nationaal registratienummer: Nl
Contact
Contactpunt: NUON Power Generation B.V.
Joseph M.G. Dela Haije